ENRIGHT CONSTRUCTION INC V RHYS MUSSMAN
Annotate this Case
Download PDF
STATE OF MICHIGAN
COURT OF APPEALS
ENRIGHT CONSTRUCTION, INC.,
UNPUBLISHED
October 11, 2005
Plaintiff/Counter-DefendantAppellee,
v
No. 256079
Marquette Circuit Court
LC No. 01-038393-CK
RHYS MUSSMAN, d/b/a ROYAL
DEVELOPMENT,
Defendant/Counter-PlaintiffAppellant.
Before: O’Connell, P.J., and Sawyer and Murphy, JJ.
PER CURIAM.
Defendant appeals as of right from the trial court’s order dismissing his final
counterclaim with prejudice and closing the case. He also challenges the trial court’s denial of
his earlier motion for summary disposition. We affirm.
Defendant claims he was entitled to summary disposition because the relevant contract
unambiguously required modifications to be in writing and because the modification clause was
not waived by the parties’ actions as a matter of law. We disagree. We review de novo a trial
court’s decision to grant summary disposition. Maiden v Rozwood, 461 Mich 109, 118; 597
NW2d 817 (1999). We agree with the trial court that summary disposition for defendant was
inappropriate because plaintiff raised a material question of fact whether the parties waived the
writing requirement.
A signed, written agreement can be modified, and strict performance can be waived,
because parties are always free to make a new, subsequent agreement. Turner v Williams, 311
Mich 563, 566; 19 NW2d 100 (1945). A waiver does not need to be established by an express
agreement, but rather it can be based purely on the parties’ actions. Id. However, such a
modification or waiver of a contract provision requires clear and convincing evidence of mutual
agreement, by actions or otherwise. Quality Products & Concepts Co v Nagel Precision, Inc,
469 Mich 362, 372; 666 NW2d 251 (2003). Viewing the evidence in plaintiff’s favor, plaintiff
provided clear and convincing evidence of the parties’ mutual assent to waive the contract’s
writing requirement.
-1-
Plaintiff sent defendant a written proposal to build a road. The proposal estimated that
materials would cost $10,000, and labor would cost $10,000 per week. One of the proposal’s
primary assumptions was that the project would only take two weeks, but the proposal explained
that “there are many variables and this can be lengthened or shortened.” The proposal also stated
that plaintiff would “follow the directions of [defendant’s] supervisor.” While these terms were
all handwritten, defendant relies on boilerplate print that stated, “Any alteration or deviation
from above specifications involving extra costs will be executed only upon written orders, and
will become an extra charge over and above the estimate.” However, other print stated, “All
agreements contingent upon . . . delays beyond our control.” Defendant signed the proposal,
apparently assenting to it as a contract.1
Plaintiff demonstrated that defendant’s agents, without putting anything in writing, asked
plaintiff to work beyond the two weeks originally estimated in the proposal. In fact, the evidence
showed that plaintiff worked on the project for twenty weeks, ten times the length of time
originally estimated, not including a winter break. Any claim that defendant expected plaintiff to
perform the extra work as part within the original $30,000 agreement is belied by the fact that
defendant, without complaint, paid plaintiff over $83,000, nearly three times the original
proposal’s estimate. Defendant claims that he paid the money because of an accounting error.
Even if this were true, the payment, viewed in a light most favorable to plaintiff, represents clear
and convincing evidence that the parties waived any writing requirement and altered the original
agreement.2 Therefore, while we do not necessarily agree with the ambiguity found by the trial
court, it did not err when it denied defendant’s motion for summary disposition because, viewed
in the light most favorable to plaintiff, there was clear and convincing evidence that the parties
waived any writing requirement. We will not reverse a trial court’s decision when it reaches the
right result. See, e.g., Hess v Cannon Twp, 265 Mich App 582, 596; 696 NW2d 742 (2005).
Defendant argues that, according to Port Huron Ed Ass’n v Port Huron Area School Dist,
452 Mich 309, 327; 550 NW2d 228 (1996), a party’s inadvertent oversight regarding a contract
provision is insufficient to establish clear and unmistakable evidence of mutual intent. However,
viewing the evidence in plaintiff’s favor, the case at bar involved a single project that took ten
times longer than estimated, involved defendant’s agents encouraging plaintiff to keep working
despite these obvious delays and additional costs, and resulted in paid invoices amounting to
almost three times the contract price. These facts indicate a situation well beyond possible
1
Defendant did not insert a date next to his signature, but plaintiff never earnestly disputed that it
was contractually bound by the terms of the proposal.
2
We note that the writing requirement actually protects plaintiff, not defendant. The
requirement states that plaintiff will not execute any alteration or deviation from the proposal
without a written order, not that the parties will never alter or deviate from the proposal without a
written addendum. The language is clearly designed to protect plaintiff from a customer’s claim
that plaintiff orally agreed to further changes and then failed to perform. Therefore, plaintiff’s
mere provision of labor and materials beyond what the proposal specified, and defendant’s
acceptance of that labor and those materials, sufficed to indicate that the parties waived any
writing as a condition to the execution of a contract modification.
-2-
mistaken payments or contractual oversights. They represent clear and convincing evidence of
the parties’ mutual assent to waive the contract’s written modification condition.3
Defendant next challenges the sanction the trial court imposed on him for not appearing
at a court-ordered settlement conference. Defendant argues that the trial court abused its
discretion when it dismissed his counterclaim with prejudice. We disagree. A trial court’s
decision to impose sanctions is reviewed for an abuse of discretion. Massey v Ferndale, 206
Mich App 698, 702; 522 NW2d 734 (1994). A court may dismiss a claim with prejudice if a
plaintiff fails to comply with a court order. MCR 2.401(G)(1). However, “[d]ismissal is a
drastic step that should be taken cautiously.” Vicencio v Ramirez, 211 Mich App 501, 506; 536
NW2d 280 (1995). “Before imposing such a sanction, the trial court is required to carefully
evaluate all available options on the record and conclude that the sanction of dismissal is just and
proper.” Id. Before dismissing a claim, the court should consider the following factors:
(1) whether the violation was wilful or accidental; (2) the party’s history of
refusing to comply with previous court orders; (3) the prejudice to the opposing
party; (4) whether there exists a history of deliberate delay; (5) the degree of
compliance with other parts of the court’s orders; (6) attempts to cure the defect;
and (7) whether a lesser sanction would better serve the interests of justice. [Id. at
507.]
Reviewing the ruling in context, the trial court did not abuse its discretion. Following the
bench trial that resulted in an award to plaintiff for its requested damages, the only remaining
issue was defendant’s counterclaim that plaintiff failed to build the road in a workmanlike
manner. The day before the settlement conference, defendant moved to have the counterclaim
dismissed without prejudice and failed to appear for the settlement conference. Trial was already
scheduled to begin a few weeks later. Defendant admits his willful violation of the court’s order
to appear. His brief indicated that he “chose not to appear at the settlement conference . . . due to
the fact that he had directed that the counterclaim be dismissed albeit without prejudice.”
However, the court was under no obligation to grant defendant’s requested dismissal, which
would have only led to further delay, so it was not a valid excuse for deliberately missing the
court-ordered settlement conference. Defendant’s claim that he was available for the settlement
conference by telephone does not lessen the willfulness of his violation, especially because he
never indicated his availability at the time of the settlement conference. The court found that
there was clear prejudice to plaintiff from further delay because the road, which plaintiff had not
worked on in nearly four years, was subject to deterioration, making it harder for plaintiff to
3
After denying summary disposition, the trial court held a bench trial and found that plaintiff
performed reasonably according to the instructions of defendant’s agents. It therefore entered
judgment in plaintiff’s favor for its unpaid invoices. Defendant does not challenge the trial
court’s ultimate findings or this final judgment. We note that the trial court’s ultimate findings
are consistent with our alternative grounds for affirming its denial of defendant’s motion for
summary disposition. The trial court found that, through his agents and in keeping with the
instructions in the original contract, defendant extended the contract to cover the additional labor
and materials needed to finish the road.
-3-
prove its workmanship at the time of completion. A sanction for plaintiff’s wasted costs would
not have addressed this additional prejudice. Therefore, the trial court did not abuse its
discretion when it sanctioned defendant with dismissal.
Affirmed.
/s/ Peter D. O’Connell
/s/ David H. Sawyer
/s/ William B. Murphy
-4-
Some case metadata and case summaries were written with the help of AI, which can produce inaccuracies. You should read the full case before relying on it for legal research purposes.
This site is protected by reCAPTCHA and the Google Privacy Policy and Terms of Service apply.