CHELSEA INVESTMENT GROUP LLC V CITY OF CHELSEA
Annotate this Case
Download PDF
STATE OF MICHIGAN
COURT OF APPEALS
CHELSEA INVESTMENT GROUP LLC,
Plaintiff-Appellee/Cross-Appellant,
v
CITY OF CHELSEA and MICHAEL STEKLAC,
FOR PUBLICATION
April 27, 2010
9:05 a.m.
No. 288920
Washtenaw Circuit Court
LC No. 06-000164-CK
Defendants-Appellants/CrossAppellees.
Before: JANSEN, P.J., AND CAVANAGH AND K. F. KELLY, JJ.
PER CURIAM.
In this contract action, defendants, city of Chelsea and Michael Steklac, and plaintiff,
Chelsea Investment Group, LLC, cross appeal the trial court’s order entering judgment in
defendants’ favor after a bench trial. We affirm in part and vacate in part.
I. FACTS AND PROCEDURAL HISTORY
In 2000, plaintiff acquired 157 acres of undeveloped real property by land contract. The
property was located in Chelsea, Michigan, and plaintiff agreed to pay $5,000,000 for the
property. Plaintiff paid $500,000 at closing, leaving $4,500,000 to be paid in equal semi-annual
installments over the next five years.1 Plaintiff also agreed to pay the property taxes.
After entering into the land contract, plaintiff filed a petition with the city of Chelsea to
rezone the property as a planned unit development (PUD). Plaintiff also filed a petition for site
plan approval for the purpose of developing single-family units. The city’s planning commission
issued two resolutions that made findings and recommendations as to plaintiff’s petitions.
Ultimately, the planning commission recommended that defendant approve the rezoning request
and the proposed development as long as plaintiff met all the provisions in the resolutions.
Accordingly, in November 2001, the property was rezoned. Further discussions ensued
1
The land was not immediately released to plaintiff; rather, it was released incrementally with
subsequent payments. However, the contract permitted plaintiff to develop infrastructure on the
property during the term of the land contract.
-1-
concerning the site plan and, in April 2002, plaintiff proposed a detailed plan for the construction
of a development called “Heritage Point,” which would contain 352 single-family
condominiums.
A. THE PUD AGREEMENT
In April 2003, the city approved this site plan and plaintiff and the city entered into a
PUD Agreement, which was recorded in the register of deeds. The PUD Agreement granted
plaintiff site plan approval for all 352 residences and required the development of Heritage Point
to be carried out in five separate phases, each phase of which contemplated the development of a
certain number of lots. Under the agreement, each phase was subject to plaintiff obtaining site
plan approval for the project from the city. In particular, no zoning or building permits could be
issued in a phase until “the public water mains, public sanitary sewers, and all appurtenances
necessary to support that phase have been installed,” approved, and accepted by defendant.
The PUD Agreement was divided into several parts: recitals, statements of mutual
agreement, plaintiff’s obligations under Part A, and the city’s obligations under Part B. The
recitals provided an account of what had occurred over the last several years with regard to the
subject property. The statements of agreement indicated that the “[PUD] zoning designation
shall consist of the findings and recommendations of the [city] Planning Commission adopted on
November 21, 2001 . . . .” In other words, the PUD Agreement incorporated a November 2001
resolution of the city’s planning commission. The resolution stated, in relevant part:
b. Sanitary sewer – The existing sanitary sewer is adequate to handle the
proposed development. However, the [waste water treatment plant] must be
expanded and 10 acres of additional land is needed for that expansion.
*
*
*
c. Water – Existing water mains cannot provide volumes or pressure needed for
the proposed 352 houses.
Part A of the PUD Agreement provided conditions under which plaintiff would develop
the property and set forth plaintiff’s contractual obligations. Plaintiff, for instance, was required
to donate 10 acres of land to defendant for the expansion of the city’s waste water treatment
plant (WWTP) and to convey a conservation easement of approximately 30 acres. Further, Part
A of the agreement indicated that it was defendant’s duty to expand the existing water capacity.
Paragraph 4 of the PUD Agreement stated:
The [city] is in the process of extending the existing 12” water main down Elm
Street . . . which 12” Water Main Work will be completed by the [city], at the
[city’s] expense, in sufficient time so as not to interfere with or delay [plaintiff’s]
development of the Property. In Consideration of the donation/conveyance of the
WWTP property . . . the [city] agrees that neither the Developer . . . nor any of the
owners of lots/units in the Development will ever be required to install (or pay to
install) any offsite improvements with regard to the provision of water to the
Development and, if there is ever a need to increase the water capacity to the
Development, the [city] will be responsible for installing any and all offsite
-2-
improvements related to increasing the water capacity to the Development
without contribution of any kind from the Developer . . . or any owners of
lots/units in the Development . . . .
Part B of the PUD Agreement contained further obligations of the city. It stated, in full:
The [city] agrees to do the following in a timely manner so as not to delay any
approvals or the issuance of any permits or certificates of occupancy in the
Development:
1. Approve PUD zoning for the Property, based on the Area/Site Plan.
2. Extend the 12” water main in Elm Street, at the [city’s] expense, to the west
line of the Property by Elm Street and Taylor Lane.
3. Mill and apply a 2” overlay to, at the [city’s] expense, the remaining segment
of Taylor Lane, between Dexter Chelsea Road and the South line of the Property,
in accordance with [city] standards and specifications so as not to delay or
interfere with the Development.
4. Construct and perform those requisite tasks, at the [city’s] expense, as
outlined above, in connection with the installation of any offsite utilities.
5. Accept street and public utilities as public facilities upon inspection, testing,
submission of as-built drawings, and approval by the [city] Engineer.
6.
To obtain any offsite easements in connection with any requisite
improvements to Dexter/Chelsea Road as provided above. (Emphasis added.)
B. THE PULTE PURCHASE AGREEMENT
In May 2004, plaintiff entered into a purchase agreement with Pulte Land Company
(Pulte) for the construction of the residential units. Under the purchase agreement, Pulte agreed
to purchase the home sites from plaintiff for $23,000 per lot. Pulte was to purchase the lots and
construct the homes in three phases, which roughly corresponded with the five phases in the
PUD Agreement. More specifically, Pulte phase one was the purchase of 76 lots which
encompassed all of PUD Agreement phase I; Pulte phase two was the purchase of 167 lots
encompassing PUD Agreement phases II and III; and, Pulte phase three was the purchase of 109
lots encompassing PUD Agreement phases IV and V.
Importantly, Pulte’s purchase of the sites was conditioned upon plaintiff’s securing
governmental approval for each phase. The purchase agreement also required Pulte to pay a
$250,000 deposit, which would be fully refundable if plaintiff failed to obtain the necessary
government approvals within certain time limits. For example, once Pulte closed on Pulte phase
one, plaintiff had a year from that date to obtain the necessary approvals for Pulte phase two. In
addition, Pulte also agreed to pay the property’s taxes.
-3-
C. PERFORMANCE
Pulte closed on Pulte phase one by August 2004. Pulte was ready to begin work on Pulte
phases two and three beginning in the summer of 2005. Thus, plaintiff sought the city’s approval
of the plans for those phases. Plaintiff’s engineer submitted the final plans to the city in March
2005.
In May 2005, the city informed plaintiff that the WWTP lacked sufficient capacity for the
development. Apparently, according to defendant Michael Steklac, the city manager, the city
was aware of a problem with the reverse osmosis (RO) system, a treatment that provided the city
with soft water, as early as 2003-2004. However, this problem related to having to change the
system’s filter too frequently; Steklac was not aware of the capacity issue until April or May of
2005. Up until that point, Steklac had believed, based on the advice of the city’s engineers, that
the earliest the city would need to address the WWTP capacity issue was within or by five years
of 2004. Steklac was surprised when he learned of the WWTP capacity issue in May 2005.
Steklac worked with plaintiff in attempts to resolve the WWTP issue. Steklac met with
the city’s engineers, considered plaintiff’s proposals, and submitted plaintiff’s proposals to the
MDEQ for consideration. Apparently, the city council refused to adopt and implement
plaintiff’s suggestion that it cease using the RO system. Had the city agreed to turn the RO
system off, the additional necessary capacity would become available, thereby allowing the
MDEQ to issue a permit. However, according to Steklac, stopping the RO system was not a
viable option. Although keeping the RO system running was not a matter of health and safety,
but an aesthetic issue, the city council voted to continue the system because citizens were paying
for soft water and the city was obligated to provide that water. Thus, the solutions contemplated
were explored in the context of keeping the RO system online.
Several months later, in June 2005, the city learned that it also had a water capacity issue.
The city’s new water superintendent had found that the city was reporting a greater water
capacity to the MDEQ than it really had. After informing the MDEQ of the lack of capacity, the
MDEQ issued a moratorium on development in July 2005. The city informed plaintiff of a water
capacity problem in July 2005. According to Steven Fisher, plaintiff’s president, these capacity
problems were a complete surprise. Although plaintiff had been aware of water moratoriums in
1999 and 2000, it had taken steps to make certain that its development would not be impacted by
any future moratoriums and had been “very sensitive” to the issue.
Plaintiff and the city continued to work together to try and solve these problems. At one
point, the city indicated that 85 lots may be available. Pulte affirmed that it would take less than
the 167 lots that it was promised under Pulte phase two because stopping its operations would be
costly. However, the city reneged on the offer of 85 lots.
Despite these efforts, by August 2005, a year after Pulte had completed phase one,
plaintiff still had not obtained the necessary governmental approvals that would permit Pulte to
proceed with the project. Thus, Pulte exercised its option under the purchase agreement to
terminate the agreement and to receive a full refund of its $250,000 deposit. By March 2006,
approximately eight months after the moratorium had been issued, the city resolved both the
-4-
WWTP and water capacity issues and the moratorium was removed. Plaintiff mitigated its
damages by entering into a contract for the sale of some of the lots with another builder.
However, plaintiff was not able to obtain a similar purchase price for the lots.
D. PRE-TRIAL PROCEDURE
On February 9, 2006, plaintiff filed suit against the city and Steklac, requesting injunctive
and declaratory relief; alleging that defendants breached the PUD Agreement by failing to
provide sufficient water and sewer capacity; alleging that defendants’ actions constituted an
unlawful taking of the property; and, alleging that Steklac was grossly negligent in carrying out
his duties such that he caused plaintiff harm.
In August 2007, defendants and plaintiff filed cross-motions for summary disposition.
The trial court denied plaintiff’s motion and granted defendants’ motion in part, dismissing the
portion of plaintiff’s claim alleging that defendants had been negligent. According to the court,
the “strategic actions related to the performance of a contract do not fall within the definition of
gross negligence that was ‘the proximate cause’ of plaintiff’s injuries.” Thus, the court found
that plaintiff’s negligence claim was barred by governmental immunity under MCL 691.1407(2).
The court, however, found that questions of fact existed as to the remaining counts and, thus,
denied summary disposition in either parties’ favor. The parties moved for summary disposition
again in June 2008, but the trial court denied both parties’ motions; in its view, questions of fact
existed as to the remaining claims.
E. BENCH TRIAL
The matter was set for a bench trial on July 25, 2008. The parties stipulated to waive live
testimony except as it related to the issue of damages and agreed to submit proposed findings of
fact and conclusions of law. At trial, Fisher testified that the total profit plaintiff would have
gained if Pulte had completed phase two was $2,349,340, as well as an additional $1,504,068
had Pulte been completed phase three. Fisher stated that Pulte also agreed to pay property taxes,
which brought the total plaintiff was to have gained from phases two and three to $3,873,524.
Because Fisher was able to sell some of the property, approximately 45 lots to another developer,
albeit at a lower price of $18,000 per lot, the total damage was reduced by $342,835, resulting in
total damage of $3,530,689. Fisher also indicated that plaintiff should be reimbursed the
$250,000 that Pulte had paid to plaintiff, but had been given back, in contemplation of
completing the contract.
At the close of trial, the court adopted plaintiff’s findings of fact and conclusions of law,
except with regard to plaintiff’s takings claim. The court found that plaintiff could not establish
a takings claim, but that it had established a breach of the PUD Agreement. It further indicated
that plaintiff’s damages would be limited to Pulte phase two.
Before the court entered its judgment, plaintiff moved for costs and attorneys fees. In its
brief in support, plaintiff argued that interest on the verdict, costs, and attorney’s fees should be
calculated at 6-month intervals from the date the complaint was filed, using the relevant interest
rate as of January 1 or July 1. Plaintiff contended that this calculation was consistent with the
plain language of MCL 600.6013(8), which allows interest on a money judgment and provides:
-5-
Except as otherwise provided in subsections (5) and (7) and subject to subsection
(13), for complaints filed on or after January 1, 1987, interest on a money
judgment recovered in a civil action is calculated at 6-month intervals from the
date of filing the complaint at a rate of interest equal to 1% plus the average
interest rate paid at auctions of 5-year United States treasury notes during the 6
months immediately preceding July 1 and January 1, as certified by the state
treasurer, and compounded annually, according to this section. Interest under this
subsection is calculated on the entire amount of the money judgment, including
attorney fees and other costs. The amount of interest attributable to that part of
the money judgment from which attorney fees are paid is retained by the plaintiff,
and not paid to the plaintiff's attorney.
In response, defendant argued that MCL 600.6013(8) requires that interest be calculated at 6
month intervals, changing on July 1 and January 1. According to defendants, this method of
calculation is the correct method because the State Supreme Court Administrators Office has
interpreted MCL 600.6013(8) in this manner (Id.).
Subsequently, the trial court entered its judgment awarding plaintiff $2,276,621 in
damages2 plus interest on that amount “through September 3, 2008, and interest subsequent to
that date until the judgment is satisfied in an amount determined pursuant to MCL 600.6013(8).”
Both parties appeal the trial court’s judgment and order.
II. DEFENDANTS’ APPEAL
Defendants raise two arguments before this Court: that the trial court erred by finding that
the city breached the PUD Agreement and by awarding plaintiff damages. We consider each
argument in turn.
A. BREACH OF CONTRACT
Defendants contend that the trial court erred by finding that the city agreed to provide
plaintiff with instantaneous access to water under the PUD Agreement and thereby breached the
PUD Agreement by failing to do so. We disagree. We review a trial court’s finding of fact in a
bench trial for clear error and its conclusions of law de novo. Ligon v Detroit, 276 Mich App
120, 124; 739 NW2d 900 (2007). A finding is clearly erroneous if there is no evidentiary
support for it or if this Court is left with a definite and firm conviction that a mistake has been
made. Hill v City of Warren, 276 Mich App 299, 308; 740 NW2d 706 (2007). The trial court’s
findings are given great deference, as it is in a better position to examine the facts. Id. Further,
to the extent that this matter requires us to interpret the meaning of the PUD Agreement, our
review is also de novo. McDonald v Farm Bureau Ins Co, 480 Mich 191, 197; 747 NW2d 811
(2008).
2
This number was calculated by taking the total profit from Pulte phase two, plus the $250,000
earnest deposit money, plus the $20,116 in property taxes, and minus $342,835 earned as a result
of plaintiff’s mitigation.
-6-
After our review of the record, we cannot conclude that the trial court clearly erred by
finding that the city breached the PUD Agreement. The agreement, by incorporating the
November 21st resolution, noted that the existing WWTP was “adequate to handle the proposed
development.” With regard to water capacity, the PUD Agreement, also through the resolution,
indicated that the existing water mains were inadequate to provide the necessary volume of water
or the necessary water pressure. However, the city explicitly agreed under Part A of the PUD
Agreement to expand the water capacity for the development at its own expense in exchange for
plaintiff’s donation of almost 40 acres of land. Part A, paragraph 4 of the PUD Agreement,
states in part:
The [city] is in the process of extending the existing 12” water main down Elm
Street . . . which 12” Water Main Work will be completed by the [city], at the
[city’s] expense, in sufficient time so as not to interfere with or delay [plaintiff’s]
development of the Property. In Consideration of the donation/conveyance of the
WWTP property . . . . [I]f there is ever a need to increase the water capacity to
the Development, the [city] will be responsible for installing any and all offsite
improvements related to increasing the water capacity to the Development
without contribution of any kind from the Developer . . . or any owners of
lots/units in the Development . . . . [Emphasis added.]
Further, under Part B of the PUD Agreement, the city explicitly agreed to “[c]onstruct and
perform those requisite tasks, at the [city’s] expense, as outlined above, in connection with the
installation of any offsite utilities” in a “timely manner so as not to delay any approvals or the
issuance of any permits or certificates of occupancy in the Development . . . .” (Emphasis
added.)
Despite its explicit promises not to interfere with or delay plaintiff’s development, the
city did exactly that. In August 2004, Pulte had completed Pulte phase one and was waiting for
plaintiff to obtain the necessary governmental approvals for the next phases of the project.
Plaintiff submitted its plans to the city in March 2005, but the city did not approve them.
Instead, in May 2005, the city reported that the WWTP lacked capacity and, in July 2005, it told
plaintiff that water capacity was also lacking and that a MDEQ moratorium had been issued
preventing development. By August of 2005, the city still had not resolved the issues, or
otherwise approved plaintiff’s plan, and Pulte exercised its right to terminate its agreement with
plaintiff. Under these circumstances, the city’s actions interfered with and delayed plaintiff’s
development of Heritage Point. Given the foregoing, we are not definitely and firmly convinced
that the trial court made a mistake when it concluded that the city breached the PUD Agreement.
Defendants, however, argue that the trial court erred to the extent that it found that the
city was required to provide “instantaneous access” to water and sewer capacity, or to otherwise
provide those services at a certain date. In defendants’ view, it was not contractually obligated to
provide water services or facilities at a certain date because the PUD Agreement is “devoid of
any timing provision.” This argument is unavailing. At the outset, this Court notes that the trial
court never made a finding that the city was required to provide plaintiff with “instantaneous
access” to water under the PUD Agreement. Nor are we of the view that the PUD Agreement
contained such a requirement, or indeed, any certain or firm date requirement.
-7-
However, we cannot agree with defendants’ contention that the PUD Agreement was
devoid of any timing provisions, or that it did not contractually obligate the city to provide such
services. While it is true that nothing in the language of the agreement required that water
services be available by a certain date, Part A paragraph 4 of the PUD Agreement did contain
language that required the city to “install[] any and all offsite improvements related to increasing
the water capacity to the development” if there is ever such a necessity. And, the city further
agreed, under Part B of the agreement, to “[c]onstruct and perform those requisite tasks, at the
[city’s] expense, as outlined above, in connection with the installation of any offsite utilities” in a
“timely manner so as not to delay any approvals or the issuance of any permits . . . .” (Emphasis
added.) Nothing in the language of Part B limits this requirement to the specific obligations
listed in part B of the PUD Agreement. Rather, the terms, “as outlined above,” when read in
context of the entire agreement and in conjunction with the phrase, “in connection with the
installation of any offsite facilities,” relates back to the provisions of paragraph 4. Thus,
defendants’ attempt to limit the city’s duties to those contained in Part B—meaning that the city
was not contractually obliged to provide water or sewer capacity—and their accompanying
contention that Part B is devoid of any timing provision fails. Clearly, the terms “timely
manner,” as used in Part B, indicate an intent to provide water services, not at a certain date or
instantaneously, but to provide them in an amount of time that would not delay approvals or
interfere with plaintiff’s development. The PUD Agreement is not devoid of a timing provision.3
Finally, defendants assert that even if the breach did occur, it was not the cause of
plaintiff’s damages. According to defendant, the cause of plaintiff’s damages was the condition
of the real estate market. We disagree. To recover in a breach of contract action, a plaintiff must
prove that the defendant’s breach was the proximate cause of the damage a plaintiff suffered.
Alan Custom Homes, Inc v Krol, 256 Mich App 505, 512; 667 NW2d 379 (2003). In other
words, the breach must be the most direct, natural, and foreseeable cause of the plaintiff’s
damages. See Unibar Maintenance Services, Inc v Saigh, 283 Mich App 609, 625; 769 NW2d
911 (2009). Here, the city’s failure to provide timely approval consistent with the PUD
Agreement was the most direct cause of the damages plaintiff suffered. Had the city provided
the approvals, Pulte would have proceeded with Pulte phase two. The fact that Pulte was willing
and ready to proceed with phase two construction with a fewer number of lots was not the result
of adverse market conditions, as defendants now argue. Rather, Pulte was willing to do so
3
Defendants also argue that the trial court erred to the extent that it found that the city failed to
provide access to water and sewer capacity within “a reasonable time.” Defendants’ argument is
based on the principle that courts may require performance of a contract to be completed within a
“reasonable time” if the contract lacks definiteness as to the time of performance. However, the
language of the PUD Agreement makes specific reference to the city’s obligation to provide
services in a “timely manner so as not to delay any approvals or issuance of any permits . . . .”
Thus, given our conclusion that the PUD Agreement is not devoid of a timing provision, it is
unnecessary for us to assume that the trial court based its conclusion on an application of the
principle that courts may infer a reasonable time for performance. Thus, we do not consider
defendants’ argument.
-8-
because the city, at one point, had offered plaintiff and Pulte the opportunity to proceed with 85
lots as opposed to 167. For all of the foregoing reasons, we conclude that the trial court did not
clearly err in concluding that the city breached the PUD Agreement.
B. DAMAGES
Defendants next contend that the trial court erred by awarding plaintiff damages for Pulte
phase two. In defendants’ view, the award should be vacated because it is too speculative. We
cannot agree. We review a trial court’s determination of damages after a bench trial for clear
error. Alan Custom Homes, Inc, 256 Mich App at 513. It is true that damages that are
speculative or based on conjecture are not recoverable. Ensink v Mecosta Co Gen Hosp, 262
Mich App 518, 525; 687 NW2d 143 (2004). However, it is not necessary that damages be
determined with mathematical certainty; rather, it is sufficient if a reasonable basis for
computation exists. Id.
Here, the trial court awarded plaintiff $2,276,621 for Pulte phase two. The award of
damages was not speculative. Rather, it was based on the testimony of Steven Fisher, plaintiff’s
president, who testified regarding how much profit plaintiff would have realized had Pulte phase
two been completed. It appears from our review of the record that Fisher’s computation was
based on the terms of purchase agreement, under which Pulte agreed to pay property taxes and to
compensate plaintiff $23,000 per lot. The measure of damages also included Pulte’s $250,000
earnest deposit, minus the amount plaintiff gained from selling some lots to a different
developer. Given this record evidence, we simply fail to see how this measure of damages is
speculative.
Further, there is no merit to defendants’ contention that the damages were speculative
because Pulte did not know whether it would complete Pulte phase two. In support, defendant
cites the testimony of Pulte’s representative, Steven Atchinson, who indicated that Pulte was
uncertain whether it would acquire more than half the Pulte phase two lots. However, a review
of Atchinson’s deposition testimony reveals that Pulte was ready and willing to proceed with
Pulte phase two; the only reason Pulte did not know whether it would complete Pulte phase two
was because the city had not approved plaintiff’s site plan and the city had only offered Pulte
half the Pulte phase two lots. Accordingly, the evidence provided permitted a reasonable basis
by which to calculate damages and the trial court did not clearly err. Defendants are not entitled
to any relief based on their claims of error raised on appeal.
II. PLAINTIFF’S CROSS APPEAL
We now consider plaintiff’s arguments raised in its cross appeal, including its allegations
that the trial court erred in measuring damages, in calculating interest, and by dismissing
plaintiff’s takings and gross negligence claims.
A. DAMAGES
Plaintiff first contends that the trial court erred by failing to award plaintiff damages for
Pulte phase three. We cannot agree because we are not convinced, after our review of the record,
that a mistake has been made. Atchinson testified that Pulte’s business plan in 2006 did include
-9-
all of Pulte phases two and three. But Atchinson also indicated that Pulte was uncertain whether
it would move forward with the entire project given the fact that it would become more difficult
to invest dollars over time. Thus, while Pulte was contemplating completion of phase three, it
remains entirely speculative whether Pulte actually would have closed on phase three. See
Ensink, 262 Mich App at 525. Pulte could have failed to close on phase three for any number or
reasons: it could have decided to terminate the contract itself due to market conditions or other
business plans. Thus, it cannot be said with certainty that plaintiff’s loss of the phase three
profits was the result of defendant’s breach of the PUD Agreement. Accordingly, the trial court
did not clearly err and plaintiff is not entitled to damages for Pulte phase three.
B. INTEREST
Plaintiff next asserts that the trial court erred by calculating interest at six-month intervals
on July 1 and January 1, inconsistently with MCL 600.6013(8). Plaintiff posits that the statute
requires that interest be calculated at six-month intervals from the date of the complaint, using
the most immediately preceding interest rate from July 1 or January 1. We agree.
At the outset, we note that it is well-established that interest is calculated from the date
the complaint is filed. See Ayar v Foodland Distributors, 472 Mich 713, 716-717; 698 NW2d
875 (2005). However, the issue of when the interest is re-calculated under the statute is one of
first-impression.4 To frame the question more concisely, we must decide whether MCL
600.6013(8) requires interest to be calculated at six-month intervals from the day the complaint
is filed, or whether it requires interest to be calculated every six months on January 1 and July 1
from the date the complaint is filed. Issues of statutory construction are questions of law
reviewed de novo on appeal. Stabley v Huron-Clinton Metro Park Auth, 228 Mich App 363,
366; 579 NW2d 374 (1998). Our goal in construing a statute is to discern the intent of the
Legislature, as expressed by the words of the statute. Computer Network, Inc v AM Gen Corp,
265 Mich App 309, 327; 696 NW2d 49 (2005). We must “presume every word is used for a
purpose, and as far as possible, . . . give effect to every clause and sentence.” Verizon North, Inc
v Public Service Comm, 263 Mich App 567, 570; 689 NW2d 709 (2004). The Court must give
all the statute’s words their plain and ordinary meanings, unless otherwise defined by the
Legislature. See Stabley, 228 Mich App at 367. If the meaning of the language is plain and
unambiguous, then we must apply the statute as written and not substitute our own policy
preferences for that of the Legislature. Lantz v Banks, 245 Mich App 621, 626; 628 NW2d 583
(2001).
4
The Michigan Supreme Court has considered the meaning of MCL 600.6013(8) on numerous
occasions but has not considered the particular question before the Court. See, e.g., Ayar v
Foodland Distributors, 472 Mich at 716-718 (concluding that the plain language of the statute
does not preclude attorney fees or costs from the interest calculation measured from the date
complaint is filed); Morales v Auto-Owners Ins Co (After Remand), 469 Mich 487, 491-492; 672
NW2d 849 (2003) (concluding that MCL 300.6013(8) calculates interest on a judgment
following such a prejudgment appellate delay, without interruption, from the date the complaint
is filed).
-10-
MCL 600.6013(8) permits an award of interest on a money judgment. It provides:
Except as otherwise provided in subsections (5) and (7) and subject to subsection
(13), for complaints filed on or after January 1, 1987, interest on a money
judgment recovered in a civil action is calculated at 6-month intervals from the
date of filing the complaint at a rate of interest equal to 1% plus the average
interest rate paid at auctions of 5-year United States treasury notes during the 6
months immediately preceding July 1 and January 1, as certified by the state
treasurer, and compounded annually, according to this section. Interest under this
subsection is calculated on the entire amount of the money judgment, including
attorney fees and other costs. The amount of interest attributable to that part of
the money judgment from which attorney fees are paid is retained by the plaintiff,
and not paid to the plaintiff's attorney. [Emphasis added.]
In our view, the language of this provision is plain and unambiguous. It requires that
“interest on a money judgment [be] calculated at 6-month intervals from the date of the filing of
the complaint at a rate of interest equal to . . . United States treasury notes during the 6 months
immediately preceding July 1 and January 1 . . . .” When this language is parsed, MCL
600.6013(8) simply requires that interest on a judgment be re-calculated every six months from
the date of the filing of the complaint using the interest rates announced on July 1 or January 1,
whichever is “immediately preceding” the complaint’s six-month anniversary date. For
example, interest on a complaint filed in August 2008 would be calculated in February 2009
using the January 1 rate, and would be calculated again in August 2009, using the July 2009 rate.
Defendants contend that the trial court’s calculation should be affirmed. They argue that
the proper interpretation of MCL 600.6013(8) mandates that interest be calculated at six-month
intervals on July 1 and January 1, starting from the date the complaint is filed. According to
defendant, this interpretation is consistent with the Michgan’s State Court Administrative
Office’s July 27, 2009, publication, entitled, “Interest rates for money judgments under MCL
600.6013.” With regard to MCL 300.6013(8), it stated:
Interest is calculated at 6-month intervals on Jan 1st and July 1st of each year,
starting from the date the complaint is filed, compounded annually. The interest
rate equals the rate paid on 5-year United States treasury notes, as certified by the
state treasurer, for the 6 months preceding each Jan 1st and July 1st, plus 1%.
We disagree. This interpretation is plainly contrary to the clear language of the statute,
which requires that interest be re-calculated at six-month intervals from the date of the
complaint, using the immediately preceding interest rate from July 1 or January 1. While some
deference is due to an administrative agency’s interpretation of a statute it is charged with
executing, Nelligan v Gibson Insulation Co, 193 Mich App 274, 281; 483 NW2d 460 (1992),
this deference is not binding on this Court and it cannot overcome the statute’s plain meaning.
Ludington Service Corp v Acting Comm’r of Ins, 444 Mich 481, 503-504; 511 NW2d 661
(1994), amended 444 Mich 1240; 518 NW2d 478 (1994). Because the SCAO’s recommendation
is contrary to the statute’s plain meaning, this Court is not bound to follow it. Thus, the interest
on plaintiff’ s judgment must be re-calculated on remand consistent with the language of MCL
600.6013(8).
-11-
C. TAKINGS CLAUSE AND SUBSTANTIVE DUE PROCESS
Plaintiff next argues that the trial court erred by dismissing its claims that defendants’
actions constituted an unlawful taking and violated its substantive due process rights. In
particular, plaintiff alleges that defendants engaged in arbitrary action that significantly and
adversely impacted plaintiff’s economic interests in the subject property. Plaintiff alleges that
defendants’ actions undermined its investment-backed expectations, which were based on
defendants’ representations in the PUD Agreement. We disagree. Following a bench trial, we
review a trial court’s conclusions of law on constitutional issues de novo. Novi v Robert Adell
Children’s Funded Trust, 473 Mich 242, 248; 701 NW2d 144 (2005).
Both the Takings Clause of the Fifth Amendment of the United States Constitution and
Const 1963, art 10, § 2 prohibit the taking of private property for public use without just
compensation. Cummins v Robinson Twp, 283 Mich App 677, 706; 770 NW2d 421 (2009). The
Takings Clause does not prohibit the government’s interference with a private individual’s
property, but requires that interferences amounting to a taking be compensated for. Id.
Typically, the government takes private property through formal condemnation proceedings.
Dorman v Clinton Twp, 269 Mich App 638, 645; 714 NW2d 350 (2006). However, government
regulations that overburden a property may also constitute a compensable taking. K & K Constr,
Inc v Dep't of Natural Resources, 456 Mich 570, 576; 575 NW2d 531 (1998). Regulatory
takings claims, that do not rise to the level of a categorical taking,5 are governed by the standard
set out in Penn Central Transporaiont Co v New York City, 438 US 104; 98 S Ct 2646; 57 L Ed
2d 631 (1978). The balancing test announced in that case requires a reviewing court to engage in
an ad hoc factual inquiry, focusing on “(1) the character of the government’s action, (2) the
economic effect of the regulation on the property, and (3) the extent by which the regulation has
interfered with distinct, investment-backed expectations.” K & K Constr, 456 Mich at 577,
quoting Penn Central, 438 US at 124. “While there is no set formula for determining when a
taking has occurred under this test, it is at least ‘clear that the question whether a regulation
denies the owner economically viable use of his land requires at least a comparison of the value
removed with the value that remains.’” K & K Constr, 456 Mich at 588 (citation omitted).
Moreover, the mere reduction in the value of regulated property is insufficient by itself to
establish that a compensable taking has occurred. Penn Central, 438 US at 131; Dorman, 269
Mich App at 647.
We agree with the trial court that plaintiff has not satisfied the Penn Central test. “The
relevant inquiries regarding the character of the government’s action is whether it singles [a]
plaintiff[] out to bear the burden for the public good and whether the regulation being challenged
‘is a comprehensive, broadly based regulatory scheme that burdens and benefits all citizens
relatively equally.’” Cummins, 283 Mich App at 720 (citation omitted). Here, the MDEQ
imposed a temporary moratorium on the issuance of water and sewer permits due to health and
5
A “categorical” taking is a physical invasion onto a landowner’s property or, also, a regulatory
taking that deprives an owner of all economically and beneficial use of his land. Lucas v South
Carolina Coastal Council, 505 US 1003, 1015; 112 S Ct 2886; 120 L Ed 2d 798 (1992).
Plaintiff does not assert such a claim in the instant matter.
-12-
safety concerns arising from the capacity of the WWTP during wet periods. As a result, the city
was temporarily precluded from issuing approvals and permits for plaintiff’s development. All
developers in the area connecting to the water facilities at issue would be subject to the same
moratoriums. Thus, plaintiff has failed to establish that the MDEQ moratorium singled it out.
Further, plaintiff has produced no evidence demonstrating the extent to which the land’s
value was diminished during the moratorium. Even assuming without deciding, that the value of
the land was diminished while the moratorium was in effect, plaintiff still would not be able to
establish a taking. This is because the land retained some value since plaintiff was free to use the
property in any other way. Further, the fact that plaintiff was not able to realize a profit similar
to that which it would have gained under the Pulte purchase agreement does not establish a
taking. “The Taking Clause does not guarantee property owners an economic profit from the use
of their land.” Paragon Properties Co v City of Novi, 452 Mich 568, 579 n 13; 550 NW2d 772
(1996).6
Finally, plaintiff cannot establish that the regulation interfered with its distinct,
investment-backed expectations. This is because plaintiff had no reasonable expectation that the
development would not be subject to obtaining city approvals for each stage of the development.
The PUD Agreement explicitly stated that no zoning or building permits could be issued in a
phase until “the public water mains, public sanitary sewers, and all appurtenances necessary to
support that phase have been installed,” approved, and accepted by the city. Moreover, we note
that plaintiff knew problems could arise regarding water facilities, due to the fact that the MDEQ
had issued moratoriums in 1995 and 2000 and plaintiff’s president’s admission that he had been
particularly sensitive to the issue during contract negotiations. Given the foregoing, plaintiff has
failed to produce evidence that would satisfy the Penn Central test. Accordingly, we conclude
that the trial court did not err in concluding that no taking of plaintiff’s property had occurred.
Lastly, we also find unavailing plaintiff’s related argument that the trial court erred by
dismissing its claim that defendants’ actions violated plaintiff’s substantive due process rights. It
is true that both the Fourteenth Amendment to the United States Constitution and Const 1963, art
1, § 17 guarantee that no state shall deprive any person of “life, liberty or property, without due
process of law.” People v Sierb, 456 Mich 519, 522; 581 NW2d 219 (1998). For the reasons
explained in the above analysis, plaintiff has failed to show that it suffered a deprivation of
property. Further, even if plaintiff had established such a deprivation, its claim would
nonetheless fail because the city’s reasons for not issuing the permits were reasonable and
legitimate. With regard to the WWTP issue, Steklac testified that the city was obligated to
provide its citizens with soft water and it could not increase capacity by stopping the RO system.
And, with regard to water capacity, the MDEQ issued the moratorium in July 2005 for health and
6
We also note that, generally, “requiring plaintiffs to obtain building and occupancy permits
cannot itself constitute a taking of property.” Cummins, 283 Mich App at 719. However, in
instances of abnormally long delays, even temporary takings may be compensable. See id. at
716-717. But no extraordinary delay occurred in the instant; the MDEQ was only in effect for a
period of eight months. The obvious implication is that once the moratorium was lifted, the
property would recover its full value.
-13-
safety reasons after it learned that the city had been mistakenly over-reporting its capacity. For
this reason, plaintiff’s substantive due process claim necessarily fails.
D. GROSS NEGLIGENCE
Plaintiff next argues that the trial court erred in granting summary disposition in
defendants’ favor as to its gross negligence claim against Steklac. We disagree. It appears from
our review of the record that the trial court granted defendants’ motion based on MCR
2.116(C)(7). We review de novo a motion brought under MCR 2.116(C)(7), which alleges that a
claim is barred because of immunity by law. Bennett v Detroit Police Chief, 274 Mich App 307,
310; 732 NW2d 164 (2006). “[S]ummary disposition is precluded where reasonable jurors
honestly could have reached different conclusions with respect to whether a defendant's conduct
amounted to gross negligence.” Kendricks v Rehfield, 270 Mich App 679; 716 NW2d 623 (2006)
(citation omitted).
Here, the trial court, citing MCL 691.1407(2), found that Steklac’s conduct did not fall
within the definition of “gross negligence” and therefore plaintiff’s negligence claim against him
was barred by governmental immunity. MCL 691.1407(2) provides, in part:
[E]ach officer and employee of a governmental agency . . . is immune from tort
liability for an injury to a person or damage to property caused by the officer . . .
in the course of employment or service . . . while acting on behalf of a
governmental agency if . . . :
*
*
*
(c) The officer’s . . . conduct does not amount to gross negligence that is the
proximate cause of the injury or damage.
MCL 691.1407(7)(A) defines “gross negligence” as “conduct so reckless as to demonstrate a
substantial lack of concern for whether an injury results.” Evidence of ordinary negligence is not
enough to establish that a government employee was grossly negligent. Maiden v Rozwood, 461
Mich 109, 122; 597 NW2d 817 (1999). Rather, there must be evidence that the employee’s
conduct was reckless. Id. And, further, the employee’s conduct must be the proximate cause of
the plaintiff’s injury.
There is no question in the present matter that Steklac, as city manager of Chelsea, was a
public employee. Nor is there any question that Steklac was acting within the scope of his
employment while working with plaintiff with regard to the PUD Agreement. Rather, the only
issue on appeal is whether Steklac’s conduct was grossly negligent. The trial court held that
Steklac was not and we find no reason to disagree. A review of the record reveals that Steklac
actively sought solutions for both the WWTP and water capacity issues. Indeed, Steklac testified
that he attempted to solve the problem by considering a broad range of solutions proposed by
both the city’s and plaintiff’s engineers. These suggestions were proposed to the MDEQ, but
were ultimately found to be unworkable. The fact that a solution was not reached before Pulte
exercised its right to terminate the purchase agreement is not evidence that Steklac’s conduct was
reckless. Nor does the fact that Steklac knew that the WWTP was not operating optimally as
early as 2003-2004 demonstrate a substantial lack of concern for whether an injury would result.
-14-
Rather, his knowledge of the issue was with regard to the proper functioning of the RO system,
not with regard to the system’s capacity. Thus, it cannot be said that Steklac intentionally
mislead plaintiff with regard to the WWTP’s capacity. Therefore, we affirm the trial court’s
decision finding that Steklac is entitled to governmental immunity on plaintiff’s claim of gross
negligence.
Affirmed in part, but vacated with respect to the trial court’s calculation of interest.
Remanded for further proceedings not inconsistent with this opinion. We do not retain
jurisdiction.
/s/ Kathleen Jansen
/s/ Mark J. Cavanagh
/s/ Kirsten Frank Kelly
-15-
Some case metadata and case summaries were written with the help of AI, which can produce inaccuracies. You should read the full case before relying on it for legal research purposes.
This site is protected by reCAPTCHA and the Google Privacy Policy and Terms of Service apply.