KEUSCH & SONS V DOUGLAS KYES
Annotate this Case
Download PDF
STATE OF MICHIGAN
COURT OF APPEALS
KEUSCH & SONS,
UNPUBLISHED
March 2, 1999
Plaintiff/Counterdefendant-Appellant,
v
No. 203787
Clinton Circuit Court
LC No. 96-007892 CH
DOUGLAS KYES and BRIGITTE KYES,
Defendants/Counterplaintiffs/Third
Party Plaintiffs-Appellees,
and
JULIUS KEUSCH, KENNETH KEUSCH and
KEITH KEUSCH,
Third-Party Defendants.
Before: Smolenski, P.J., and Saad and Gage, JJ.
PER CURIAM.
Plaintiff appeals as of right from a $7,808.65 judgment for defendants. We conditionally affirm,
but remand for further factual findings.
In June of 1994, the parties entered into a home construction contract pursuant to which plaintiff
agreed to build defendants’ house. Plaintiff began construction the next month. After numerous
changes to the construction plans and alleged interferences by defendants, and numerous delays in
progress allegedly caused by plaintiffs, the parties met in June of 1995 and reached an agreement
providing specific times by which plaintiff would complete certain unfinished portions of defendants’
house. In August 1995, the parties met again, at which time the contract was terminated. Plaintiff
claimed this was a mutual decision, and that the only unresolved issue remained how much defendants
owed. Defendants claimed that they unilaterally terminated the contract due to plaintiff’s breach.
Plaintiff then filed suit for breach of contract, foreclosure of lien, account stated and quantum meruit.
-1
Defendants filed a counterclaim for breach of contract, violation of Builders Trust Fund Act,1 cloud of
title, and violation of the Michigan Consumer Protection Act,2 and also filed a similar third-party
complaint against Julius, Keith and Kenneth Keusch individually. The actions proceeded to a six-day
bench trial that resulted in a $7,808.65 judgment for defendants.
Plaintiff first contends that the trial court erred in not determining whether the parties in August
1995 mutually agreed to terminate their contract after plaintiff’s alleged breach. The record contains
conflicting accounts of the August 1995 meeting. The trial court made no specific finding on this
termination issue, but concluded that plaintiff had breached the parties’ agreement and that defendants
had not. However, regardless of whether plaintiff breached the contract, the parties may have
subsequently agreed to terminate, or rescind, the contract. Strom-Johnson Constr Co v Riverview
Furniture Store, 227 Mich 55, 67; 198 NW 714 (1924). If the parties so agreed, then the lower
court likely awarded an inappropriate measure of damages in calculating defendants’ damages flowing
from plaintiff’s breach. See Kundel v Portz, 301 Mich 195, 210; 3 NW2d 61 (1942) (Recission is
governed by equitable principles, one of which is that an essential prerequisite to the receipt of such
relief is the return of what has been received, or its equivalent.); Adams v Edward M Burke Homes,
Inc, 14 Mich App 578, 166 NW2d 34 (1968) (Recission involves a restoration of the status quo as to
both parties.). While the trial court likely rejected the theory that defendants agreed to waive their rights
under the parties’ agreement, without such an explicit finding by the trial court it is possible that the court
failed to consider the effect of an effective waiver and recission following plaintiff’s breach. Therefore,
we remand for a determination whether the parties in August 1995 mutually terminated the contract, or
whether defendants merely informed plaintiff of their intent to unilaterally rescind based on plaintiff’s
breach. Maynard v Dorner, 53 Mich App 568, 574; 220 NW2d 161 (1974) (Citing the predecessor
rule to MCR 2.517, this Court remanded because there were contested issues of fact left unresolved by
the trial court’s opinion).3
Plaintiff next claims that the trial court clearly erred in finding that plaintiff failed to perform its
contract in a timely manner where the evidence established that defendants’ house was a custom house
that required additional building time and where defendants made substantial changes throughout the
project. In support of this argument, plaintiff compares the progress it made on defendants’ house with
the progress made by the builder who replaced plaintiff (Truelove). Plaintiff argues that within
approximately fifteen months it had completed seventy to seventy-five percent of defendants’ house,
while it took Truelove approximately nine months to complete the remaining twenty-five percent.4
Looking at these figures, plaintiff’s completion within fifteen months of seventy-five percent of the house
seems very reasonable when, at Truelove’s pace, the work would have taken approximately twenty
seven months. However, trial testimony revealed that Truelove was less experienced than plaintiff and
that Truelove needed to complete some repairs on that portion of the house completed by plaintiff.
Furthermore, plaintiff’s argument on appeal ignores testimony produced by plaintiff at trial that, without
further modifications by defendants, it could have finished the remainder of the house within four to six
weeks. If the remaining twenty-five percent should have taken four to six weeks to complete, as
plaintiff alleged, then the initial seventy-five percent should have been completed, without modifications,
within twelve to eighteen weeks. However, it took plaintiff over three times this amount of time,5 at least
an extra forty-two weeks. Although plaintiff alleged that defendants made substantial modifications
-2
during construction of the initial seventy-five percent portion, the record revealed several unexplained
construction delays by plaintiff. Considering all these factors, we are not left with a definite or firm
conviction that the trial court erred in finding that plaintiff failed to complete defendants’ house within a
reasonable amount of time. Hoffman v Auto Club Ins Ass’n, 211 Mich App 55, 98-99; 535 NW2d
529 (1995).
Lastly, plaintiff argues that defendants waived any alleged breach by encouraging plaintiff to
continue working on the house after the parties met in June of 1995. Plaintiff contends that because the
trial court found it in breach, the court erroneously failed to recognize such a waiver. However, the trial
court found that plaintiff had breached the contract in not completing the house by August of 1995. An
alleged June waiver by defendants of a breach occurring before June was not inconsistent with the
court’s finding. While the trial court did not make an explicit finding regarding the effect of the June
meeting, such a finding is not necessary for a resolution of this issue. It is undisputed that the parties met
in June 1995 to reach an agreement regarding completion of the house. Defendants’ permitting plaintiff
to continue working on the house and acceptance of plaintiff’s further services may have constituted a
waiver of any existing breach. Schware v Derthick, 332 Mich 357, 364; 51 NW2d 305 (1952). Yet,
even assuming that the parties waived any pre-June breach and agreed to additional contract terms in
June, as evidenced by their signed agreement, the record still supports a finding that plaintiff
subsequently breached that modified contract by failing to perform within the time frames established by
the June agreement. Therefore, the trial court did not err in finding plaintiff in breach. Hoffman, supra.
We remand to the trial court for further findings of fact regarding the effect of the parties’
August 1995 meeting. We retain jurisdiction.
/s/ Michael R. Smolenski
/s/ Hilda R. Gage
/s/ Brian K. Zahra
1
MCL 570.151 et seq.; MSA 26.331 et seq.
2
MCL 445.901 et seq.; MSA 19.418(1) et seq.
3
After this Court had remanded to the trial court for additional factual findings, the case returned to this
Court for review of the trial court’s further findings in Maynard v Dorner (Supplemental Opinion), 56
Mich App 7; 223 NW2d 338 (1974).
4
Timothy Truelove estimated that by August 1995 plaintiff had completed approximately sixty-five
percent of the house. Plaintiff produced testimony at trial that by August 1995 it had completed seventy
to eighty percent of the house. For the purpose of addressing plaintiff’s argument on appeal, we will
give plaintiff the benefit of the doubt and adopt the high seventy-five percent figure it has submitted in its
brief on appeal.
5
Plaintiff alleged in its brief on appeal that it had spent approximately fifteen months working on the
initial seventy-five percent of defendants’ house. Fifteen months at four weeks per month equals sixty
weeks.
-3
Some case metadata and case summaries were written with the help of AI, which can produce inaccuracies. You should read the full case before relying on it for legal research purposes.
This site is protected by reCAPTCHA and the Google Privacy Policy and Terms of Service apply.