TERRY E. FORCHT; NELDA L. BARTON-COLLINGS; HEALTH SYSTEMS, INC. AND CORBIN NURSING HOME, INC. v. J. M. BURNS & ASSOCIATES, INC. AND TOTAL COMFORT CORPORATION AND J. M. BURNS & ASSOCIATES v. TERRY E. FORCHT; NELDA L. BARTON-COLLINGS; CORBIN NURSING HOME, INC. AND HEALTH SYSTEMS, INC.
Annotate this Case
Download PDF
RENDERED: July 2, 1999; 10:00 a.m.
NOT TO BE PUBLISHED
C ommonwealth O f K entucky
C ourt O f A ppeals
NO.
1998-CA-000560-MR
TERRY E. FORCHT; NELDA L.
BARTON-COLLINGS; HEALTH
SYSTEMS, INC. AND CORBIN
NURSING HOME, INC.
v.
APPELLANTS
APPEAL FROM WHITLEY CIRCUIT COURT
HONORABLE JERRY D. WINCHESTER, JUDGE
ACTION NOS. 96-CI-686, 96-CI-702, 96-CI-703
J. M. BURNS & ASSOCIATES, INC.
AND TOTAL COMFORT CORPORATION
APPELLEES
AND
NO. 1998-CA-000598-MR
J. M. BURNS & ASSOCIATES
v.
CROSS-APPELLANT
CROSS-APPEAL FROM WHITLEY CIRCUIT COURT
HONORABLE JERRY D. WINCHESTER, JUDGE
ACTION NOS. 96-CI-686, 96-CI-702, 96-CI-703
TERRY E. FORCHT; NELDA L.
BARTON-COLLINGS; CORBIN
NURSING HOME, INC. AND
HEALTH SYSTEMS, INC.
CROSS-APPELLEES
OPINION
AFFIRMING
** ** ** ** **
BEFORE:
GARDNER, KNOPF AND McANULTY, JUDGES.
GARDNER, JUDGE:
Appellants appeal from a judgment of the Whitley
Circuit Court for the appellees in this breach of contract
action.
J. M. Burns and Associates (Burns) has filed a cross-
appeal.
After reviewing the issues raised by the parties, this
Court affirms the circuit court’s judgment.
The owners of the Corbin Nursing Home which include
Terry Forcht, Nelda L. Barton-Collings and Health Systems,
Incorporated, hired Burns to serve as general contractor for
construction of a new nursing home in Whitley County, Kentucky.
In February 1996, the parties entered into a contract wherein
they agreed that the date of substantial completion of the
project would be November 6, 1996.
Substantial completion was
defined as the date when a certificate of occupancy would be
obtained from the Kentucky Department of Housing, Buildings and
Construction.
Problems between the owners and Burns began developing
after commencement of the project.
Burns apparently fell behind
schedule in the spring of 1996, because of very wet weather.
Burns requested that additional days be added to the completion
date, but the owners refused.
Burns has claimed that the owners
refused to change the order and design for a range hood which the
state would not approve, and that the owner failed to have an
adequate water supply provided for the project.
The owners have
maintained that Burns was back on schedule during the summer of
1996 and should have completed the project on time.
-2-
On October 25, 1996, Burns submitted a draw request to
the owners’ architect for work already performed.
According to
the request, the project was ninety percent complete and there
remained $1,110,347.07 due under the contract, of which
$730,633.90 was requested.
The architect approved the request
for $730,633.90 on November 5.
Burns maintains that the owners
failed to pay the request when due and as a result, it twice
noticed the owners that pursuant to the terms of the contract it
would stop work at the close of business on November 25, 1996, if
the amount was not paid.
On November 22, 1996, Burns claims that without giving
it notice, the owners placed a cable across the road leading to
the project and locked out Burns and its subcontractors.
The
owners subsequently hired another contractor to complete the job.
Burns maintains that the owners attempted to force as many of its
subcontractors as possible to return to the project and finish
their work.
Burns subsequently filed suit against the owners,
initially alleging $1,068,068.70 in compensatory damages.
It
also sought punitive damages, but this claim was later dismissed
by summary judgment.
Burns.
The jury reached a verdict of $602,550 for
The circuit court additionally granted Burns interest at
the rate of eight percent per annum from and after November 8,
1996, until such sums were paid in full.
The owners have
appealed, and Burns has filed a cross-appeal.
The owners first contend that the trial court
incorrectly denied their motion for a directed verdict and
-3-
judgment notwithstanding the verdict (JNOV).
They specifically
maintain that even assuming weather-related delays were
permissible under the parties’ agreement, Burns never satisfied
the two requirements of the agreement concerning weather delays.
They also argue that Burns failed to prove the damages that it
was awarded on the breach of contract claim.
After reviewing the
arguments raised by the owners, we have found no error and thus
affirm on those issues.
In general, upon review of the evidence supporting a
judgment entered based upon a jury verdict, an appellate court’s
role is limited to determining whether the trial court erred in
failing to grant a motion for directed verdict.
Lewis v. Bledsoe
Surface Mining Co., Ky, 798 S.W.2d 459, 461 (1990).
The
reviewing court must take all evidence which favors the
prevailing party as true, and the court must not determine
credibility or the weight which should be given to the evidence.
Id.
The prevailing party also is entitled to all reasonable
inferences which may be drawn from the evidence.
Id.
“Upon
completion of such an evidentiary review, the appellate court
must determine whether the verdict is palpably or flagrantly
against the evidence so as to indicate that it was reached as a
result of passion or prejudice.”
Id., at 461-62, quoting
National Collegiate Athletic Association, By and Through
Bellarmine College v. Hornung, Ky., 754 S.W.2d 855, 860 (1988).
If the reviewing court concludes affirmatively, it will find that
the trial court erred in denying the motion for directed verdict;
otherwise the court must affirm the judgment.
-4-
Id., at 462.
We first turn to the owners’ argument that Burns failed
to produce evidence meeting the requirements for permitting the
substantial completion date to be changed based upon weather
related conditions.
The contract at paragraph 29 stated that it
was understood that the contract for construction would not have
a penalty clause for late completion.
It also provided that the
substantial completion date was November 6, 1996, with due
allowances for adverse weather conditions.
The owners maintain
that the contract also provided that if adverse weather
conditions were the basis for a claim of additional time, such a
claim would be documented by data substantiating that weather
conditions were abnormal for the period of time and could not
have been reasonably anticipated.1
They maintain pursuant to
O’Bryan v. Massey-Ferguson, Inc., Ky., 413 S.W.2d 891, 893
(1966), and other authorities, that in the absence of an
ambiguity, a written instrument will be enforced strictly
according to its terms.
Because of the many added and
conflicting conditions in the contract at issue, we do not
believe that it is clear and unambiguous.
Nevertheless, Burns
presented ample evidence below to withstand a motion for directed
verdict on this issue.
Evidence from David Hall, an architect
1
The contract contains contradictory provisions regarding
weather-related delays. The two provisions cited above allow
delays based upon weather-related conditions. Two later
provisions state that there shall be no increase in the length of
the contract due to weather-related conditions and that the
contractor in submitting its bid certified that weather
conditions were taken into account and accommodated in its
proposed completion days. The owner seems to maintain that the
provision requiring Burns to meet two conditions in order to
receive an extension for weather-related conditions controls.
-5-
with Eiche and Associates who was project manager for the nursing
home construction, and others was presented showing that in the
early stages of the project, far above normal rainfall had
occurred, thus preventing the setting of the foundation and
delaying the project.
Additionally, evidence was presented that
the owners’ own actions, such as refusing to allow modification
of a range hood so that state approval could result and their
failure to have an ample water supply at the construction site,
delayed the project as well.
Sufficient evidence was also
presented which showed that Forcht, the primary owner, refused to
consider any extensions based upon weather-related delays and
refused to meet with Burns to discuss such issues.
Thus, there
was evidence to support the verdict regarding weather-related
delays.
The owners’ claim that Burns failed to prove the
damages that it was awarded on the breach of contract claim also
lacks merit.
It has long been held that a jury should not be
allowed to engage in speculation or guesswork as to the probable
damages resulting from a breach of contract.
Commonwealth of
Kentucky, Dept. of Highways v. Jent, Ky., 525 S.W.2d 121, 122
(1975), Barley’s Adm’x. v. Clover Splint Coal Co., 286 Ky. 218,
150 S.W.2d 670 (1941); Union Cotton Co. v. Bondurant, 188 Ky.
319, 222 S.W. 66 (1920).
“Loss of anticipated profits as an
element of recoverable damages for breach of contract is fully
recognized in Kentucky.”
Illinois Valley Asphalt, Inc. v. Harry
Berry, Inc., Ky., 578 S.W.2d 244, 245 (1979).
Mere uncertainty
as to the amount will not necessarily preclude recovery.
-6-
Id.
A
party however must present sufficient evidence from which a
reasonable inference as to the amount of damages can be based.
Id., at 246.
“The measure of damages under an ordinary contract,
where the defendant has prevented the plaintiff from performing
any part thereof, is the net profit which would have been made;
that is, the difference between the contract price and the
reasonable cost of performance.”
Koplin v. Faulkner, Ky., 293
S.W.2d 467, 469 (1956).
In the instant case, Burns presented ample evidence to
support an award of damages based upon a breach of contract by
the owners.
Burns presented evidence that the total construction
cost was $2,337,555 and that it had spent $1,776,349 up to the
date that it was shut out, and still owed subcontractors $53,416.
The contract balance after the draw request was $1,110,350.
Thus, there was evidence to support the $602,560 that was awarded
to Burns.
We decline to disturb the trial court’s decision not
to grant a directed verdict for the owners.
The owners next contend that the trial court
erroneously denied their motion for a new trial.
three grounds for a new trial:
They assert
(1) the trial court improperly
instructed the jury on weather-related excuses for Burns’s
nonperformance; (2) the trial court improperly instructed the
jury on liability and damages; and (3) the trial court improperly
excluded videotape evidence displaying the incomplete and
defective nature of the project in late November of 1996.
This Court has uncovered no error regarding the
instructions provided to the jury.
-7-
First, the owners’ argument
regarding the instructions addressing weather-related delays is
basically a rehashing of their prior argument wherein they
maintained that Burns failed to produce evidence to meet the
requirements under the contract for weather-related delays.
Second, the owners’ argument regarding alleged improper
instructions on liability and damages also is unfounded.
They
maintain that the trial court failed to present their theory of
the case in the instructions and that the court should have given
the jury a setoff instruction.
We have reviewed the instructions
and the authorities cited by the owners, including Shreve v.
Biggerstaff, Ky. App., 777 S.W.2d 616 (1989), and 2 John S.
Palmore and Ronald W. Eads, Kentucky Instructions to Juries,
§38.05 (1989), but believe these authorities do not apply to the
instant case and have found no error.
The trial court in this
case was presented with a complex case in which fault was being
claimed on both sides.
The court presented the jury with a
series of alternative instructions by which the jury could decide
whether the November 22, 1996, work stoppage was caused primarily
by the owners or Burns, and whether Burns had substantially
complied with the contract.
The jury was also permitted to
determine whether damages were due to Burns or the owners.
was more than a mere setoff case.
This
After hearing the evidence and
considering the instructions, the jury found in favor of Burns.
We decline to disturb the judgment based upon the jury’s verdict.
The owners have also failed to present any reversible
error concerning the trial court’s decision not to allow them to
present the entire videotape depicting alleged incomplete and
-8-
defective conditions at the project in late November 1996.
Relevancy of evidence is a determination which rests largely in
the discretion of the trial court.
Green River Electric Corp. v.
Nantz, Ky. App., 894 S.W.2d 643, 645 (1995).
An appellate court
must not disturb a trial court’s ruling absent an abuse of
discretion.
Id.
Kentucky Rule of Evidence (KRE) 103(a) states
that error may not be predicated upon a ruling which admits or
excludes evidence unless a substantive right of the party is
affected.
Id.
The owners at trial did not present the excluded
videotape evidence by avowal.
Thus, we do not know whether the
evidence would have added to their case, and we will not presume
that it would.
(1974).
See Williams v. Payne, Ky., 515 S.W.2d 618, 619
Further, we have found no abuse of discretion by the
trial court.
The court permitted the owners to show part of the
videotape which depicted alleged outright defects but would not
permit them to show uncompleted items that would have been
finished or corrected had Burns not been shut out.
The trial
court appeared to be very diligent in attempting to be fair to
both parties.
The owners finally argue that the trial court
erroneously denied their motion to amend the judgment, because it
had incorrectly awarded Burns prejudgment interest.
This Court
has found no clear error or abuse of discretion by the trial
court on this issue.
In certain instances, interest may be an appropriate
part of consequential damages.
Nucor Corp. v. General Electric
-9-
Co., Ky., 812 S.W.2d 136, 143 (1991).
The decision whether to
award interest rests with the trial court, primarily because it
involves a matter of equity.
Id.
A court is not as much
concerned with whether the claim is liquidated or unliquidated as
it is with whether justice and equity demand an allowance of
interest to the injured party.
Ky., 293 S.W.2d 470 (1956).
Id.; quoting Dalton v. Mullins,
See also Friction Materials Co. v.
Stinson, Ky. App., 833 S.W.2d 388, 392 (1992).
An award of
interest is within the judicial discretion of the trial court.
Nucor Corp. v. General Electric Co., 812 S.W.2d at 143.
Murray v. McCoy, Ky. App., 949 S.W.2d 613, 615 (1996).
See also
The
Supreme Court adopted the rule set out in Restatement (Second) of
Contracts §354,
(1) If the breach consists of a failure to
pay a definite sum in money or to render a
performance with fixed or ascertainable
monetary value, interest is recoverable from
the time for performance on the amount due
less all deductions to which the party in
breach is entitled.
(2) In any other case, such interest may be
allowed if justice requires on the amount
that would have been just compensation had it
been paid when performance was due.
Nucor Corp. v. General Electric Co., 812 S.W.2d at 144.
In the instant case, the trial court properly acted
within its discretion in awarding prejudgment interest to Burns.
Specifically, it awarded Burns interest at eight percent per
annum from and after November 8, 1996, until such sums were paid
in full.
The contract in this case provided at paragraph 7.2
that payments due and payable under the contract shall bear
interest from the date payment is due at the rate of eight
-10-
percent.
The amount of damages in this case could be ascertained
without too much difficulty based upon the contract, the agreed
upon price, the amounts already paid and still owed to Burns, and
the amounts Burns owed subcontractors.
The evidence shows that
the owners locked out Burns and did not permit it to complete the
project.
The circuit court carefully weighed the facts and the
applicable law in setting the interest, and we decline to disturb
its ruling.2
For the foregoing reasons, the Whitley Circuit Court’s
judgment is affirmed.
ALL CONCUR.
BRIEF FOR APPELLANTS/CROSS
APPELLEES:
BRIEF FOR APPELLEE/CROSSAPPELLANT:
Byron E. Leet
Louisville, Kentucky
Michael R. Eaves
Richmond, Kentucky
Wesley R. Tipton
Corbin, Kentucky
2
In its cross-appeal, Burns raises the issue of punitive
damages. It concedes that under existing law, punitive damages
are not warranted unless this Court determines that Forcht’s
conduct and bad faith rises to the level of a tort. We have
uncovered no error by the trial court on this issue and thus,
affirm.
-11-
Some case metadata and case summaries were written with the help of AI, which can produce inaccuracies. You should read the full case before relying on it for legal research purposes.
This site is protected by reCAPTCHA and the Google Privacy Policy and Terms of Service apply.