2015 US Code
Title 28 - Judiciary and Judicial Procedure (Sections 1 - 5001)
Part IV - Jurisdiction and Venue (Sections 1251 - 1631)
Chapter 91 - United States Court of Federal Claims (Sections 1491 - 1509)
Sec. 1499 - Liquidated damages withheld from contractors under chapter 37 of title 40
Publication Title | United States Code, 2012 Edition, Supplement 3, Title 28 - JUDICIARY AND JUDICIAL PROCEDURE |
Category | Bills and Statutes |
Collection | United States Code |
SuDoc Class Number | Y 1.2/5: |
Contained Within | Title 28 - JUDICIARY AND JUDICIAL PROCEDURE PART IV - JURISDICTION AND VENUE CHAPTER 91 - UNITED STATES COURT OF FEDERAL CLAIMS Sec. 1499 - Liquidated damages withheld from contractors under chapter 37 of title 40 |
Contains | section 1499 |
Date | 2015 |
Laws In Effect As Of Date | January 3, 2016 |
Positive Law | Yes |
Disposition | standard |
Source Credit | June 25, 1948, ch. 646, 62 Stat. 942; Pub. L. 87-581, title II, §202(a), Aug. 13, 1962, 76 Stat. 360; Pub. L. 97-164, title I, §133(e)(1), (2)(A), Apr. 2, 1982, 96 Stat. 40, 41; Pub. L. 101-650, title III, §325(b)(7), Dec. 1, 1990, 104 Stat. 5121; Pub. L. 102-572, title IX, §902(a)(1), Oct. 29, 1992, 106 Stat. 4516; Pub. L. 107-217, §3(g)(3), Aug. 21, 2002, 116 Stat. 1299; Pub. L. 109-284, §4(2), Sept. 27, 2006, 120 Stat. 1211. |
Statutes at Large References | 37 Stat. 137 62 Stat. 942 76 Stat. 360 96 Stat. 40 104 Stat. 5121 106 Stat. 4516 116 Stat. 1299 120 Stat. 1211 |
Public and Private Laws | Public Law 87-581, Public Law 97-164, Public Law 101-650, Public Law 102-572, Public Law 107-217, Public Law 109-284 |
Download PDF
The United States Court of Federal Claims shall have jurisdiction to render judgment upon any claim for liquidated damages withheld from a contractor or subcontractor under section 3703 of title 40.
(June 25, 1948, ch. 646, 62 Stat. 942; Pub. L. 87–581, title II, §202(a), Aug. 13, 1962, 76 Stat. 360; Pub. L. 97–164, title I, §133(e)(1), (2)(A), Apr. 2, 1982, 96 Stat. 40, 41; Pub. L. 101–650, title III, §325(b)(7), Dec. 1, 1990, 104 Stat. 5121; Pub. L. 102–572, title IX, §902(a)(1), Oct. 29, 1992, 106 Stat. 4516; Pub. L. 107–217, §3(g)(3), Aug. 21, 2002, 116 Stat. 1299; Pub. L. 109–284, §4(2), Sept. 27, 2006, 120 Stat. 1211.)
HISTORICAL AND REVISION NOTESBased on section 324 of title 40, U.S.C., 1940 ed., Public Buildings, Property and Works (June 19, 1912, ch. 174, §1, 37 Stat. 137).
This section contains only the jurisdictional provision in the last clause of section 324 of title 40, U.S.C., 1940 ed.
Changes in phraseology were made.
AMENDMENTS2006—Pub. L. 109–284 substituted "chapter 37 of title 40" for "Contract Work Hours and Safety Standards Act" in section catchline.
2002—Pub. L. 107–217 substituted "section 3703 of title 40" for "section 104 of the Contract Work Hours and Safety Standards Act".
1992—Pub. L. 102–572 substituted "United States Court of Federal Claims" for "United States Claims Court".
1990—Pub. L. 101–650 substituted "Hours and Safety Standards" for "Hours Standards" in text.
1982—Pub. L. 97–164 substituted "Contract Work Hours and Safety Standards Act" for "Contract Work Hours Standards Act" in section catchline and "United States Claims Court" for "Court of Claims" in text.
1962—Pub. L. 87–581 amended section generally, substituting "Liquidated damages withheld from contractors under Contract Work Hours Standards Act" for "Penalties imposed against contractors under eight hour law" in section catchline, and "liquidated damages withheld from a contractor or subcontractor under section 104 of the Contract Work Hours Standards Act" for "a penalty withheld from a contractor or subcontractor under section 324 of Title 40" in text.
EFFECTIVE DATE OF 1992 AMENDMENTAmendment by Pub. L. 102–572 effective Oct. 29, 1992, see section 911 of Pub. L. 102–572, set out as a note under section 171 of this title.
EFFECTIVE DATE OF 1982 AMENDMENTAmendment by Pub. L. 97–164 effective Oct. 1, 1982, see section 402 of Pub. L. 97–164, set out as a note under section 171 of this title.
EFFECTIVE DATE OF 1962 AMENDMENTAmendment by Pub. L. 87–581 effective 60 days after Aug. 13, 1962, but shall not affect contracts existing or thereafter entered into pursuant to invitations for bids outstanding on Aug. 13, 1962, see section 204 of Pub. L. 87–581, Aug. 13, 1962, 76 Stat. 360.
CONTINUED JURISDICTION UPON CLAIMS UNDER SECTION 324 OF FORMER TITLE 40Pub. L. 87–581, title II, §202(b), Aug. 13, 1962, 76 Stat. 360, provided that the Court of Claims (now United States Court of Federal Claims) was to continue to have jurisdiction to render judgment upon certain claims for a penalty withheld from a contractor or subcontractor under section 324 of former Title 40, Public Buildings, Property, and Works, in connection with any contract subject to that section existing on the date sixty days after Aug. 13, 1962, or thereafter entered into pursuant to invitations for bids that were outstanding on Aug. 13, 1962.
Disclaimer: These codes may not be the most recent version. The United States Government Printing Office may have more current or accurate information. We make no warranties or guarantees about the accuracy, completeness, or adequacy of the information contained on this site or the information linked to on the US site. Please check official sources.