2005 Minnesota Statutes - 103E.541 — Extension of time on contracts.

     103E.541 Extension of time on contracts. 


    The auditors of affected counties may extend the time for 
 the performance of a contract as provided in this section.  The 
 contractor may apply, in writing, for an extension of the 
 contract.  Notice of the application must be given to:  (1) the 
 engineer and the attorney for the petitioners; and (2) for a 
 joint county drainage project, to the auditors of the affected 
 counties.  The auditors may grant an extension if sufficient 
 reasons are shown.  The extension does not affect a claim for 
 liquidated damages that may arise after the original time 
 expires and before an extension or a claim that may arise after 
 the time for the extension expires.  


    HIST: 1990 c 391 art 5 s 73