There is a newer version of this Section
2022
2021
2020
2019 (you are here)
2018
Other previous versions
View our newest version here

2019 Kentucky Revised Statutes
Chapter 26A - Court of justice
26A.168 Reports on status of court facilities projects and contingency fund.

Universal Citation: KY Rev Stat § 26A.168 (2019)
Previous Next

Download as PDF
26A.168 Reports on status of court facilities projects and contingency fund. (1) (2) The Administrative Office of the Courts shall provide to the Capital Projects and Bond Oversight Committee, at the committee's January, April, July, and October regular meetings, a status report of all incomplete court facilities projects. The Capital Projects and Bond Oversight Committee shall prescribe data elements for the quarterly status reports. For each project, the status report shall include: (a) The project title; (b) The county in which the project is located; (c) The scope and use allowance authorized for the project in the judicial branch budget, and any increases to the scope or use allowance under KRS 26A.164; (d) The current status of the project; (e) Estimated completion date of the project; (f) An explanation of any delay or major change in the project, including deletion or modification of project components; and (g) Any other information that the committee requests. On August 1 of each year, the Administrative Office of the Courts shall prepare a financial report on the court facility use allowance contingency fund for the fiscal year ending on June 30 of that year. The report shall include, with explanations, allotments, expenditures, encumbrances, and the available balance. Effective: June 8, 2011 History: Amended 2011 Ky. Acts ch. 73, sec. 4, effective June 8, 2011. -- Amended 2002 Ky. Acts ch. 328, sec. 2, effective July 15, 2002. -- Created 2000 Ky. Acts ch. 496, sec. 6, effective July 14, 2000.
Previous Next
Disclaimer: These codes may not be the most recent version. Kentucky may have more current or accurate information. We make no warranties or guarantees about the accuracy, completeness, or adequacy of the information contained on this site or the information linked to on the state site. Please check official sources.
This site is protected by reCAPTCHA and the Google Privacy Policy and Terms of Service apply.