2016 Colorado Revised Statutes
Title 13 - Courts and Court Procedure
Limitation of Actions
Article 80 - Limitations - Personal Actions
§ 13-80-104. Limitation of actions against architects, contractors, builders or builder vendors, engineers, inspectors, and others
(1) (a) Notwithstanding any statutory provision to the contrary, all actions against any architect, contractor, builder or builder vendor, engineer, or inspector performing or furnishing the design, planning, supervision, inspection, construction, or observation of construction of any improvement to real property shall be brought within the time provided in section 13-80-102 after the claim for relief arises, and not thereafter, but in no case shall such an action be brought more than six years after the substantial completion of the improvement to the real property, except as provided in subsection (2) of this section.
(b) (I) Except as otherwise provided in subparagraph (II) of this paragraph (b), a claim for relief arises under this section at the time the claimant or the claimant's predecessor in interest discovers or in the exercise of reasonable diligence should have discovered the physical manifestations of a defect in the improvement which ultimately causes the injury.
(II) Notwithstanding the provisions of paragraph (a) of this subsection (1), all claims, including, but not limited to indemnity or contribution, by a claimant against a person who is or may be liable to the claimant for all or part of the claimant's liability to a third person:
(A) Arise at the time the third person's claim against the claimant is settled or at the time final judgment is entered on the third person's claim against the claimant, whichever comes first; and
(B) Shall be brought within ninety days after the claims arise, and not thereafter.
(c) Such actions shall include any and all actions in tort, contract, indemnity, or contribution, or other actions for the recovery of damages for:
(I) Any deficiency in the design, planning, supervision, inspection, construction, or observation of construction of any improvement to real property; or
(II) Injury to real or personal property caused by any such deficiency; or
(III) Injury to or wrongful death of a person caused by any such deficiency.
(2) In case any such cause of action arises during the fifth or sixth year after substantial completion of the improvement to real property, said action shall be brought within two years after the date upon which said cause of action arises.
(3) The limitations provided by this section shall not be asserted as a defense by any person in actual possession or control, as owner or tenant or in any other capacity, of such an improvement at the time any deficiency in such an improvement constitutes the proximate cause of the injury or damage for which it is proposed to bring an action.
Disclaimer: These codes may not be the most recent version. Colorado may have more current or accurate information. We make no warranties or guarantees about the accuracy, completeness, or adequacy of the information contained on this site or the information linked to on the state site. Please check official sources.