Washington Revised Code RCW 4.24.360: Construction contract provision waiving, releasing, etc., rights of contractor, etc., to damages or adjustment for unreasonable delay caused by contractee, etc. — Declared void and unenforceable — Exceptions.

Code Resources

Washington Resources
Washington Website
Washington Governor
Washington Legislature
Washington Courts

Search this Code
in Google Scholar

on the Web
Google Web Search
MSN Web Search
Yahoo! Web Search

in the News
Google News Search
Google News Archive Search
Yahoo! News Search

in the Blogs
BlawgSearch.com Search
Google Blog Search
Technorati Blog Search

in other Databases
Google Book Search

    Any clause in a construction contract, as defined in RCW 4.24.370, which purports to waive, release, or extinguish the rights of a contractor, subcontractor, or supplier to damages or an equitable adjustment arising out of unreasonable delay in performance which delay is caused by the acts or omissions of the contractee or persons acting for the contractee is against public policy and is void and unenforceable.

         This section shall not be construed to void any provision in a construction contract, as defined in RCW 4.24.370, which (1) requires notice of delays, (2) provides for arbitration or other procedure for settlement, or (3) provides for reasonable liquidated damages.

    [1979 ex.s. c 264 § 1.]