There is a newer version of the Minnesota Statutes
2012 Minnesota Statutes
Chapters 103A - 114B — Water
Chapter 103E — Drainage
GENERAL PROVISIONS- Section 103E.005 — Definitions
- Section 103E.011 — Drainage Authority Powers
- Section 103E.015 — Considerations before Drainage Work is Done
- Section 103E.021 — Ditches Must Be Planted with Perennial Vegetation
- Section 103E.025 — Procedure for Drainage Project That Affects State Land or Water Area Used for Conservation
- Section 103E.031 — Connection with Drains in Adjoining States
- Section 103E.035 — Defective Notice
- Section 103E.041 — Personal Service in Lieu of Other Methods of Notice
- Section 103E.043 — Informal Meetings
- Section 103E.045 — Failure of Drainage Authority to Attend Hearings
- Section 103E.051 — Defective Proceedings
- Section 103E.055 — Reimbursement of Cost of Former Surveys When Used Later
- Section 103E.061 — Right of Entry
- Section 103E.065 — Drainage Inspectors
- Section 103E.067 — Ditch Buffer Strip Annual Reporting
- Section 103E.071 — County Attorney
- Section 103E.075 — Obstruction of Drainage System
- Section 103E.081 — Crimes Related to Drainage Systems; Penalties
- Section 103E.085 — Enforcement
- Section 103E.091 — Appeals
- Section 103E.095 — Appeal from Orders Dismissing or Establishing Drainage Systems
- Section 103E.097 — Payment of Attorney Fees on Appeal
- Section 103E.101 — Drainage Proceeding and Construction Records
- Section 103E.105 — Advice About Drainage Questions
- Section 103E.111 — Field Surveys and Investigations by Director
- Section 103E.115 — Hydrological and Drainage Information
- Section 103E.121 — Drain Tile Manufacturing Studies
- Section 103E.202 — Petitions
- Section 103E.212 — New Drainage System Projects
- Section 103E.215 — Improvement of Drainage System
- Section 103E.221 — Improvement of Outlets
- Section 103E.225 — Laterals
- Section 103E.227 — Impounding, Rerouting, and Diverting Drainage System Waters
- Section 103E.231 — Dismissal or Delay of Proceedings by Petitioners
- Section 103E.235 — Drainage System in Two or More Counties
- Section 103E.238 — County Attorney Review of Petition and Bond
- Section 103E.241 — Engineer
- Section 103E.245 — Preliminary Survey and Preliminary Survey Report
- Section 103E.251 — Filing Preliminary Survey Report
- Section 103E.255 — Commissioner's Preliminary Advisory Report
- Section 103E.261 — Preliminary Hearing
- Section 103E.265 — Order for Detailed Survey and Detailed Survey Report
- Section 103E.271 — Detailed Survey
- Section 103E.275 — Engineer's Variance from Drainage Authority Order
- Section 103E.281 — Soil Survey
- Section 103E.285 — Detailed Survey Report
- Section 103E.291 — Filing Detailed Survey Report
- Section 103E.295 — Revision of Engineer's Detailed Survey Report after Acceptance
- Section 103E.301 — Commissioner's Final Advisory Report
- Section 103E.305 — Viewers' Appointment and Qualification
- Section 103E.311 — Viewers' Duties
- Section 103E.315 — Assessment of Drainage Benefits and Damages
- Section 103E.321 — Viewers' Report
- Section 103E.323 — Property Owners' Report
- Section 103E.325 — Final Hearing Notice
- Section 103E.331 — Jurisdiction of Property by Drainage Authority
- Section 103E.335 — Proceedings at the Final Hearing
- Section 103E.341 — Drainage Authority Final Order
- Section 103E.345 — Apportionment of Cost for Joint County Drainage Systems
- Section 103E.401 — Use of Drainage System As an Outlet
- Section 103E.405 — Outlets in Adjoining States
- Section 103E.411 — Drainage System As Outlet for Municipality
- Section 103E.501 — Contract and Bond
- Section 103E.505 — Awarding the Construction Contract
- Section 103E.511 — Procedure If Contract is Not Awarded Due to Bids or Costs
- Section 103E.515 — Damages, Payment
- Section 103E.521 — Supervision of Construction
- Section 103E.525 — Construction and Maintenance of Bridges and Culverts
- Section 103E.526 — Construction of Road Instead of Bridge or Culvert
- Section 103E.53 — Rules to Standardize Forms
- Section 103E.531 — Inspection of Drainage Construction and Partial Payments
- Section 103E.535 — Partial Payment of Retained Contract Amounts
- Section 103E.541 — Extension of Time on Contracts
- Section 103E.545 — Reduction of Contractor's Bond
- Section 103E.551 — Contractor's Default
- Section 103E.555 — Acceptance of Contract
- Section 103E.601 — Drainage Lien Statement
- Section 103E.605 — Effect of Filed Drainage Lien
- Section 103E.611 — Payment of Drainage Liens and Interest
- Section 103E.615 — Enforcement of Assessments
- Section 103E.621 — Satisfaction of Liens
- Section 103E.625 — Subdivision by Platting Must Have Liens Apportioned
- Section 103E.631 — Apportionment of Liens
- Section 103E.635 — Drainage Bond Issues
- Section 103E.641 — Drainage Funding Bonds
- Section 103E.645 — Allowance and Payment of Fees and Expenses
- Section 103E.651 — Drainage System Account
- Section 103E.655 — Payment of Drainage System Costs
- Section 103E.661 — Examination and Establishment of Drainage System Accounts by State Auditor
- Section 103E.701 — Repairs
- Section 103E.705 — Repair Procedure
- Section 103E.711 — Cost Apportionment for Joint County Drainage Systems
- Section 103E.715 — Procedure for Repair by Petition
- Section 103E.721 — Replacement and Hydraulic Capacity of Bridges and Culverts
- Section 103E.725 — Cost of Repair
- Section 103E.728 — Apportionment of Repair Costs
- Section 103E.731 — Assessment; Bonds
- Section 103E.735 — Drainage System Repair Fund
- Section 103E.741 — Inclusion of Property That Has Not Been Assessed Benefits
- Section 103E.745 — Cost of Repair Exceeding Benefits in Anoka County
Disclaimer: These codes may not be the most recent version. Minnesota may have more current or accurate information. We make no warranties or guarantees about the accuracy, completeness, or adequacy of the information contained on this site or the information linked to on the state site. Please check official sources.
This site is protected by reCAPTCHA and the Google
Privacy Policy and
Terms of Service apply.
