There is a newer version of the Kentucky Revised Statutes
2009 Kentucky Revised Statutes
CHAPTER 26A COURT OF JUSTICE
26A.168 Reports on status of court facilities projects and contingency fund.
Download pdfregular meetings, a status report of all incomplete court facilities projects. The
Capital Projects and Bond Oversight Committee shall prescribe data elements for
the quarterly status reports. For each project, the status report shall include:
(a) The project title;
(b) The county in which the project is located;
(c) The scope and use allowance authorized for the project in the judicial branch budget and budget memorandum, and any increases to the scope or use
allowance under KRS 26A.164; (d) The current status of the project;
(e) Estimated completion date of the project;
(f) An explanation of any delay or major change in the project, including deletion or modification of project components; and (g) Any other information that the committee requests. (2) On August 1 of each year, the Administrative Office of the Courts shall prepare a financial report on the court facility use allowance contingency fund for the fiscal
year ending on June 30 of that year. The report shall include, with explanations,
allotments, expenditures, encumbrances, and the available balance. Effective: July 15, 2002
History: Amended 2002 Ky. Acts ch. 328, sec. 2, effective July 15, 2002. -- Created 2000 Ky. Acts ch. 496, sec. 6, effective July 14, 2000.
Disclaimer: These codes may not be the most recent version. Kentucky may have more current or accurate information. We make no warranties or guarantees about the accuracy, completeness, or adequacy of the information contained on this site or the information linked to on the state site. Please check official sources.
This site is protected by reCAPTCHA and the Google
Privacy Policy and
Terms of Service apply.